Search results

Construction delay always causes massive damage to the advancing construction industries, which is no different in the case of Bangladeshi construction industries. This paper aims to investigate the major delay factors causing construction delays in public-funded, mixed and private-funded construction projects of Bangladesh. Also, it offers preventive suggestions from expert stakeholders to reduce the recurrence of delays.

At first, an extensive literature review was conducted to identify the thirty-seven major delay factors categorized under seven groups. A questionnaire was then developed for survey at ongoing construction projects at a different division of Bangladesh. Next, data from 110 respondents were collected, and the delay factors were ranked based on the Relative Importance Index (RII); lastly, probable solutions were suggested for top-ranked delay factors based on opinions from expert stakeholders in the construction sector of Bangladesh.

The overall RII ranking of the 37 delay factors showed “Construction mistakes and defective work,” “Contract modifications by the client” and “Adverse weather condition” as the top three factors causing the delay. For public-funded projects, “Construction mistakes and defective work” and “Slow decision making by a consultant” are the top delay factors. For mixed projects, “Slow decision making of the client” and “Construction mistakes and defective work ranked top, and for private-funded projects, “Financial problems and payment delay of the client” and “Adverse weather condition” ranked top. These nuances of ranking in individual project types ascertain that the causes of delay vary in terms of project features.

The outcome of this project will help identify the significant delay factors based on their severity of effectiveness associated with public-funded, mixed and private-funded projects in Bangladesh. The suggestions regarding preventing these delay factors obtained through the opinions of expert stakeholders can help reduce the effect of these delays in the context of Bangladesh and in countries where the similarity in construction environment prevails.

Previously, studies on construction delays in Bangladesh focused mainly on identifying the delays using qualitative analysis techniques. This study is based on a unique methodology of integrating quantitative research on delay factor identification and qualitative research on preventive measures following the opinions gathered from expert stakeholders in the construction sector.

With the aim to provide a global view of factors affecting mark-up size on construction projects, this study performs a meta-analytical review of the relevant studies over the past 20 years.

The analytical process involved the identification and evaluation of the importance of critical factors affecting mark-up size on construction projects, and the assessment of the generalisability of findings of the meta-analysis. A random-effects model was adopted in the statistical meta-analysis.

The results show that there are 23 critical factors, and the top five factors are: (1) competitiveness of other bidders; (2) number of bidders; (3) relationship and past experience with client; (4) experience on similar project; and (5) project size. A heterogeneity test further shows that there is no statistically significant heterogeneity across the studies, reinforcing the generalisability of the findings to a global context.

The list of critical factors from a global perspective should form a good basis for future efforts in bidding model development.

The research findings have practical implications to both construction clients and contractors in formulating their contracting practices and strategies.

This is the first meta-analysis of a sizeable collection of replicated studies on factors affecting mark-up size on construction projects in the literature.

This study aims to investigate the determinants of anti-corruption disclosures by construction firms in Asia-Pacific countries.

The sample comprises construction companies from seven Asia-Pacific countries from 2015 to 2019. The authors hand-collected data on anti-corruption disclosures by using content analysis.

This study provides empirical evidence that government ownership, country-level accounting competence and high-quality auditors increase companies’ anti-corruption disclosures. Meanwhile, this study finds that uncertainty avoidance does not affect companies’ anti-corruption disclosures.

This study has a number of implications. First, government and professional accountant organizations need to improve accountants’ knowledge and competence through education, training and continuous professional development. Second, public accounting firms need to ensure the quality of their auditors, particularly in the technical competence in financial and nonfinancial reporting. Finally, universities must improve and update their curriculum regarding nonfinancial reporting issues.

This study is among the first to examine anti-corruption disclosure practices in the most corrupted settings, i.e. the construction industry in Asia-Pacific countries. It uses the isomorphism perspective to explain the influence of government ownership, country-level accounting competence and high-quality auditors on anti-corruption disclosure transparency. The number of prior studies investigating this association is very limited. Moreover, disclosures of anti-corruption information are complex and sensitive; thus, coercive, normative and mimetic pressures are required to achieve higher transparency and sustainability.

This study aims to identify the enabling factors for Building Information Modeling (BIM) adoption in Vietnamese construction enterprises and uncover their interrelationships. This will help stakeholders focus on controlling and allocating resources (time, personnel, and costs) appropriately to adopt BIM and differentiate themselves from fierce competition in the architectural, engineering, construction and operations (AECO) industry.

This study first identifies and evaluates 32 enabling factors for applying BIM in the Vietnamese construction industry according to the TOE extended framework. Afterwards, a hybrid questionnaire survey using a convenient sampling method is conducted to capture stakeholders' views. The exploratory factor analysis (EFA) and the partial least squares structural equation modelling (PLS-SEM) technique are then applied to identify the constructs of the enabling factors and their interrelationships.

The study extracts six constructs that could have a significant impact on the adoption of BIM in construction enterprises, namely: technical feasibility (TF), human resources and management (HRM), company business vision (CBV), political environment (PE), economic viability (EV), and legal aspects (LA). Based on eleven proposed hypotheses, the analysis results confirm nine hypotheses and show that the HRM, TF, and CBV have the strongest effects on managers in evaluating the factors for BIM.

The results of the study fill the gap in knowledge by discovering the interrelationships among the enabling factors for BIM adoption in construction enterprises. The results might support the construction enterprises and their stakeholders in increasing the application of BIM, and digital transformation in construction industry.