Search results

Construction projects commonly encounter complicated delay problems. Over the past few decades, numerous delay analysis methods (DAMs) have been developed. There is no consensus on whether existing DAMs effectively resolve delays, particularly in the case of complex concurrent delays. Thus, the primary objective of this study is to undertake a comprehensive and systematic literature review on concurrent delays, aiming to answer the following research question: Do existing delay analysis techniques deal with concurrent delays well?

This study conducts a comprehensive review of concurrent delays by both bibliometric and systematic analysis of research publications published between 1982 and 2022 in the Web of Science (WoS) and Scopus databases. For quantitative analysis, a bibliometric mapping tool, the VOSviewer, was employed to analyze 68 selected publications to explore the co-occurrence of keywords, co-authorship and direct citation. Additionally, we conducted a qualitative analysis to answer the targeted research question, identify academic knowledge gaps and explore potential research directions for solving the theoretical and practical problems of concurrent delays.

Concurrent delays are a critical aspect of delay claims. Despite DAMs developed by a limited number of research teams to tackle issues like concurrence, float consumption and the critical path in concurrent delay resolution, practitioners continue to face significant challenges. This study has successfully identified knowledge gaps in defining, identifying, analyzing and allocating liability for concurrent delays while offering promising directions for further research. These findings reveal the incompleteness of available DAMs for solving concurrent delays.

The outcomes of this study are highly beneficial for practitioners and researchers. For practitioners, the discussions on the resolution process of concurrent delays in terms of identification, analysis and apportionment enable them to proactively address concurrent delays and lay the groundwork for preventing and resolving such issues in their construction projects. For researchers, five research directions, including advanced DAMs capable of solving concurrent delays, are proposed for reference.

Existing research on DAMs lacks comprehensive coverage of concurrent delays. Through a scientometric review, it is evident that current DAMs do not deal with concurrent delays well. This review identifies critical knowledge gaps and offers insights into potential directions for future research.

Research on strategic alliances is concerned with two issues: continuation and reconfiguration. Building on prior research that examines the two issues separately, the paper studies them simultaneously. This paper aims to investigate how strategic alliances may exert the synergetic effect between dynamics and stability as well as to discuss the dynamic evolution process and influence factors of strategic alliances.

This paper describes the construction of a two-party evolutionary game model of alliance and partners. The model is used to analyze the evolution process of synergetic mechanism to determine when to terminate and when to continue with a partnership. Further, numerical simulation is used to quantify the results and to gain insight into the effects of various factors on the dynamic evolution of the synergetic mechanism.

This paper reveals several synergetic states of dynamics and stability in the alliances. The results show that synergy states are positively affected by the collaborative innovation benefits, alliance management capability, the intensity of intellectual property protection, liquidated damages and reputation losses, and negatively affected by the absorptive capacity of partners.

The study helps the alliance to achieve long-term development as well as to balance the paradoxical relationship. The results suggest that managers of strategic alliances should focus on building strong and long-term relationships in order to achieve high performance innovations. Managers should also pay close attention to their partners’ behaviors in previous alliances.

This paper provides new insights into the paradoxical relationship in alliance by revealing the evolution of synergetic mechanism between dynamics and stability. The results remind alliances to understand the relationship between dynamics and stability and to notice the influence factors of synergistic effects when they are making decisions.

Construction delay always causes massive damage to the advancing construction industries, which is no different in the case of Bangladeshi construction industries. This paper aims to investigate the major delay factors causing construction delays in public-funded, mixed and private-funded construction projects of Bangladesh. Also, it offers preventive suggestions from expert stakeholders to reduce the recurrence of delays.

At first, an extensive literature review was conducted to identify the thirty-seven major delay factors categorized under seven groups. A questionnaire was then developed for survey at ongoing construction projects at a different division of Bangladesh. Next, data from 110 respondents were collected, and the delay factors were ranked based on the Relative Importance Index (RII); lastly, probable solutions were suggested for top-ranked delay factors based on opinions from expert stakeholders in the construction sector of Bangladesh.

The overall RII ranking of the 37 delay factors showed “Construction mistakes and defective work,” “Contract modifications by the client” and “Adverse weather condition” as the top three factors causing the delay. For public-funded projects, “Construction mistakes and defective work” and “Slow decision making by a consultant” are the top delay factors. For mixed projects, “Slow decision making of the client” and “Construction mistakes and defective work ranked top, and for private-funded projects, “Financial problems and payment delay of the client” and “Adverse weather condition” ranked top. These nuances of ranking in individual project types ascertain that the causes of delay vary in terms of project features.

The outcome of this project will help identify the significant delay factors based on their severity of effectiveness associated with public-funded, mixed and private-funded projects in Bangladesh. The suggestions regarding preventing these delay factors obtained through the opinions of expert stakeholders can help reduce the effect of these delays in the context of Bangladesh and in countries where the similarity in construction environment prevails.

Previously, studies on construction delays in Bangladesh focused mainly on identifying the delays using qualitative analysis techniques. This study is based on a unique methodology of integrating quantitative research on delay factor identification and qualitative research on preventive measures following the opinions gathered from expert stakeholders in the construction sector.

Green innovation in supply chains is crucial for socioeconomic development and stability. Factors that influence collaborative green innovation in the supply chain are complex and diverse. Exploring the main influencing factors and their mechanisms is essential for promoting collaborative green innovation in supply chains. Therefore, this study analyzes how upstream and downstream enterprises in the supply chain collaborate to develop green technological innovations, thereby providing a theoretical basis for improving the overall efficiency of the supply chain and advancing green innovation technology.

Based on evolutionary game theory, this study divides operational scenarios into pure market and government-regulated operations, thereby constructing collaborative green innovation relationships in different scenarios. Through evolutionary analysis of various entities in different operational scenarios, combined with numerical simulation analysis, we compared the evolutionary stability of collaborative green innovation behavior in supply chains with and without government regulation.

Under pure market mechanisms, the higher the green innovation capability, the stronger the willingness of various entities to collaborate in green innovation. However, under government regulation, a decrease in green innovation capability increases the willingness to collaborate with various entities. Environmental tax rates and green subsidy levels promote collaborative innovation in the short term but inhibit collaborative innovation in the long term, indicating that policy orientation has a short-term impact. Additionally, the greater the penalty for collaborative innovation breaches, the stronger the intention to engage in collaborative green innovation in the supply chain.

We introduce the factors influencing green innovation capability and social benefits in the study of the innovation behavior of upstream and downstream enterprises, expanding the research field of collaborative innovation in the supply chain. By comparing the collaborative innovation behavior of various entities in the supply chain under a pure market scenario and government regulations, this study provides a new perspective for analyzing the impact of corresponding government policies on the green innovation capability of upstream and downstream enterprises, enriching theoretical research on green innovation in the supply chain to some extent.

The concept of working capital management (WCM) has been a fundamental financial accounting term that has evolved in financial theory for centuries. Given that the construction industry (CI) is financially dynamic, there is an imperative need to understand its WCM practices. The call for the industry players to adhere to efficient financial management practices as a result of a huge financing gap requires consented effort. This study aims to explore the trend of practices of WCM in the CI and elicit a broader polemic dialogue about this crucial theme.

The source of information for the study was secondary mainly from referenced journals and international conference papers published on WCM relating to the CI. A three-step sample selection strategy was adopted to identify the range and scope of publications on WCM in the CI based on the systematic literature review method.

The CI cannot boost of enough empirical WCM research to gain in-depth understanding of its practical trend. The developing economies are failing to produce insightful peer-reviewed papers on WCM to assist in bridging the infrastructural financing gap through apposite strategies. Gaining appropriate knowledge of the short-term financial operations through a conceptualization of WCM practices in the CI may lead to better strategies formulated for smooth operations.

This is a pioneering paper in developing economies that have taken stock of WCM knowledge of the practical trend in the CI. Future research prospects in which WCM matters can use it as a reference point.

States have intervened with legislation to improve cashflow within construction project supply chains. The operation of the UK’s Housing Grants, Construction and Regeneration Act 1996 leads to payment obligations stated either as a contract administrator’s certificate (or equivalent) or an adjudicator’s decision. The purpose of the intervention would be defeated unless there are speedy ways of transforming these pieces of paper into real money. The combination of the legislation, contractual provisions and insolvency law has produced a minefield of complexity concerning enforcement of payment obligations stated in these documents. Unfortunately, the knowledge and understanding required to navigate these complexities have been sorely lacking. The purpose of this paper is to plug this gap.

Legal research methods and case study approaches, using relevant court decisions as data, were adopted.

The enforcement method advised by the court is the summary judgment procedure provided under the Civil Procedure Rules. An overdue payment obligation, either under the terms of a construction contract or an adjudicator’s decision, amounts to a debt that can be the subject of insolvency proceedings. Although the insolvency enforcement method has been successfully used on some occasions, using it purely as a debt collection weapon would be inappropriate and likely to be punished by the court.

The paper contributes to knowledge in two ways: (i) it maps out the factual situations in which these payment challenges arise in language accessible to the construction industry’s professions; and (ii) comparative analysis of payment enforcement methods to aid decision-making by parties to construction industry contracts. It is relevant to the other common-law jurisdictions in which similar statutory interventions have been made.

The COVID-19 pandemic caused significant societal changes and altered how much of the construction industry operates. This study investigates the impacts of pandemic-related changes, how these changes may apply to different companies, and which changes should continue post-pandemic.

We aim to identify pandemic-driven changes that have affected the construction workplace and the advantages and challenges associated with them. We then make recommendations for what could and should endure through the pandemic and beyond, and under what circumstances. To achieve this objective, we conducted both qualitative and quantitative analyses of 40 semi-structured interviews with US-based construction professionals.

Identified through these interviews were 21 pandemic-driven changes across six categories: management and planning, technology, workforce, health and safety, supply chain, and contracts. This study noted both positive and negative impacts of the changes on cost, schedule, productivity, collaboration, employee retention, flexibility, quality, and risk mitigation. Participants indicated that some changes should remain after the pandemic and others (e.g. select safety measures, schedule adjustments) should be temporary.

By incorporating these lessons learned into recommendations, the findings of this study will help businesses identify and implement the most appropriate improvements for their organizations. The findings also provide policymakers with valuable insights on how to promote innovation in the construction industry and potentially enact more effective policies during crises to drive long-term improvements.

The process of predicting construction costs and forecasting price fluctuations is a significant and challenging undertaking for project managers. This study aims to develop a construction cost index (CCI) for Jordan’s construction industry using fuzzy analytic hierarchy process (FAHP) and predict future CCI values using traditional and machine learning (ML) techniques.

The most influential cost items were selected by conducting a literature review and confirmatory expert interviews. The cost items’ weights were calculated using FAHP to develop the CCI formula.

The results showed that the random forest model had the lowest mean absolute percentage error (MAPE) of 1.09%, followed by Extreme Gradient Boosting and K-nearest neighbours with MAPEs of 1.41% and 1.46%, respectively.

The novelty of this study lies within the use of FAHP to address the ambiguity of the impact of various cost items on CCI. The developed CCI equation and ML models are expected to significantly benefit construction managers, investors and policymakers in making informed decisions by enhancing their understanding of cost trends in the construction industry.

The purpose of this paper is to explore the high-quality development (HQD) strategy of Chinese mineral resource enterprises, which is important for Chinese mineral resource enterprises to improve the efficiency and benefit of resource utilization, reduce the intensity of resource and energy consumption and gradually form resource-saving and environment-friendly enterprises.

This study establishes an evaluation index system with four dimensions: economy, environment, society and management innovation. The entropy value method assigns weights to them and then uses the system dynamics (SD) model for case simulation.

The results of the SD simulation conclude that the fulfillment of social responsibility and the implementation of management innovation can accelerate the realization of HQD of mineral resource enterprises; profitability plays a crucial role in economic indicators; the improvement of energy-saving volume has the most significant impact on environmental benefits; the social contribution is the key element to measure social indicators; and the sales rate of core products has the most significant impact on the benefits of management innovation.

Based on the few studies on the evaluation of the development strategy of mineral resource enterprises, this study establishes an evaluation index system that considers the interactions between indicators, combines the entropy value method with SD and uses the SD model to comprehensively and systematically analyze the impact and degree of each factor on the HQD of mineral resource enterprises.

Change orders are a typical occurrence in building projects. Change orders indirectly affect labor productivity, resulting in a significant delay in the completion of a building project. Change orders cause labor productivity losses that are difficult to describe, establish and account for contractors and subcontractors. This study aimed to look at the influence of change orders on labor productivity and develop methods to mitigate their adverse effects.

To assess the change orders' impact on productivity levels a system dynamic model was developed and devise ways were developed to counteract these negative impacts in this research. The impact of change orders on labor productivity and project time was then controlled using techniques established. Finally, a case study of KUET's hall extension was chosen, and the model and principles developed were implemented.

This study established that if the project delivery date is set and change orders are occurring often, labor productivity will be impacted. With adequate monitoring and supplemental management techniques, it can be reduced by prolonging the project.

The developed policies aid to mitigate the effect of change orders on labor productivity.