Search results

The purpose of this paper is to reveal the main causes of delays in the projects are from the client (relative importance index (RII)=0.716), labor and equipment (RII=0.701) and contractor (RII=0.698). Hence determining the contractual responsibility of delay is the most likely source of dispute in construction projects and many techniques have been used in the courts to demonstrate the criticalities of a delay event on the project schedule. Therefore, authors try to investigate all process-based techniques of delay claims and evaluated and conformed them with principles by Society of Construction Law (SCL) protocol and Association for the Advancement of Cost Engineering International (AACEI) in order to choose the best techniques based on the specific circumstances of each project.

This section is divided into two distinct parts: refers to the methods used to assess the perceptions of clients, consultants, and contractors on the relative importance of causes of delay in construction industry; and refers to advantages and disadvantages of various techniques used to analyze delays and their conform with SCL protocol. A questionnaire was developed to assess the perceptions of clients, consultants, and contractors on the relative importance of causes of delay in Iranian construction industry. The respondents were asked to indicate their response category on 78 well-recognized construction delay factors identified by authors.

In total, 78 causes of delay were identified through research. The identified causes are combined into seven groups. The field survey included 58 contractors, 55 consultants, and 62 client. Data collected were analyzed by RII and Statistical Package for Social Sciences (SPSS). The authors identified main causes of delay and ten most important causes, according to Table AII, from the perspective of three major groups of participants (clients, consultants and contractors). The ranking of categories of causes of delay, according to Table I, were: client-related causes (RII=0.716); labor and equipment category causes (RII=0.701); contractor-related causes (RII=0.698); material-related causes (RII=0.690); design-related causes (RII=0.666); external causes (RII=0.662); and consultant-related causes (RII=0.662). But according to the discussions and given that determining the contractual responsibility of delay is the most likely source of dispute in construction industry and many techniques have been used in the courts to demonstrate the criticalities of a delay event on the project schedule.

All process-based techniques of delay analysis have been present in this paper and categorized in 11 groups. In order to understand the advantages and disadvantages of them by clients, contractor and consultant, a thorough review conducted to reveal the nature of techniques. In the next step, given that selecting the most appropriate technique based on constraints and specific conditions of each project is one of the most important steps to carry out a successful delay analysis. The authors conformed, all process-based techniques of delay analysis, by SCL protocol and AACEI principles. Finally, the result of this match was brought in order to choose the best technique based on the specific circumstances of each project.

Governments worldwide seek to optimize value in public project bids. Social procurement (SP) has become a global tool for achieving project goals. The purpose of this study is to assess the understanding of SP among contractors and identify its drivers to optimize the value associated with public projects.

A total of 15 major contractors were interviewed to obtain their views on SP, appreciate their current practices and identify the main drivers of SP in projects. A semistructured interview was used to gather relevant data. Neo-institutional theory is the lens of the study used to provide the focus of the research. The collected data were analyzed using the thematic data analysis technique.

The study found that SP is understood as corporate social responsibility and is not handled in a structured manner guided by policies or clearly defined procedures. Additionally, research has shown that compliance requirements, rather than value and goodwill, are the main inspiration for SP practices.

The study’s limitation is the fact that it was conducted in the context of Botswana and only used the interview technique as the solo data collection method. The other limitation is the lack of empirical literature on SP concerning the lack of SP policy in Botswana.

This study raises awareness of the concept of SP among contractors in Botswana and eases its implementation within the industry.

The paper aims to investigate the prevailing institutional logics that underpin the organisational behaviours of Chinese contractors and the institutional complexity they face across several strategic areas when they undertake projects abroad.

The paper draws mainly on industry literature, reports and government websites to develop a typology of two ideal types of institutional logics that prevail among Chinese international contractors. The configurations of institutional complexity in different strategic areas are analysed through pattern-matching.

Two main logics are identified, namely, construction and investment logics. These logics in turn lead to patterns of volatile complexity in the strategic areas of business, technology, human resources and marketing; patterns of aligned complexity in operational and information technology strategic areas; and patterns of segregated complexity in financial strategic area.

The paper presents an ongoing doctoral research. It provides a preliminary understanding of the institutional logics affecting Chinese international contractors and sets out the first step to understand the relationship between complex institutional environments and organisational responses.

Chinese international contractors commonly face resistance, and at times resentment, from the local industries in the countries they operate. The findings of this paper are a first step towards a better understanding of why this is the case and what can be done to rectify the situation and improve long and short-term project performance.

This paper provides practical implications for Chinese contractors to understand their internal context of institutional complexity and provides the basis for further understanding of Chinese contractors’ strategic responses.

This paper aims to provide decision support for precast concrete contractors about both precast concrete supply chain strategies and construction configurations.

This paper proposes a simulation-based optimisation for supply chain and construction (SOSC) during the planning phase of PC building projects. The discrete event simulation is used to capture the characteristics of supply chain and construction processes, and calculate construction objectives under different plans. Particle swarm optimisation is combined with simulation to find optimal supply chain strategies and construction configurations.

The efficiency of SOSC is compared with the parametric simulation approach. Over 70 per cent of time and effort used to simulate and compare alternative plans is saved owing to SOSC.

Building simulation model costs a lot of time and effort. The data requirement of the proposed method is high.

The proposed SOSC approach can provide decision support for PC contractors by optimising supply chain strategies and construction configurations.

This paper has two contributions: one is in providing a decision support tool SOSC to optimise both supply chain strategies and construction configurations, while the other is in building a prototype of SOSC and testing it in a case study.

In most developing countries, indigenous emerging construction contractors (ECCs) face severe problems of not adopting a project management framework (PMF) in their business activities. It has increased their business risk and threatened their sustainability. Studies showed that government policy support (GPS) helps mitigate business risks. Thus, there is a paucity of literature concerning GPS on emerging Nigerian construction contractors' business sustainability. Therefore, the paper aims to investigate the moderating effect of GPS on the relationship between PMF and ECCs in Nigeria.

SmartPLS was used to analyse the collected data from the useable 310 questionnaires retrieved from respondents in Abuja and Lagos, Nigeria. Systems Theory was used to support the developed framework.

Findings show that government policy support significantly moderates the relationships between PMF and ECCs in the Nigerian construction sector. It implies that the study's results offer more understanding regarding issues affecting construction entrepreneurs' sustainable business cycle via applying PMF to mitigate business sustainable associated risks.

The study will stir Nigeria's ECCs and policymakers to promote construction business sustainability for a new entrepreneur, emphasising business risk management via PMF and GPS to enhance the sustainable business cycle.

The research (PMF and GPS) is strategies to enhance ECCs business sustainability in the Nigerian construction sector and other developing countries with similar political and economic attributes. Besides the study guiding old and intending ECCs and policymakers in the developing countries industries, it would contribute to bridge the theoretical gap regarding PMF and ECC, especially ECCs in developing countries with similar business sustainability issues.

Early contractor involvement (ECI) faces many barriers because it differs from traditional business practices. Public owners, especially, face a major challenge because they must comply with international and national legislation. The purpose of this paper is to develop a framework that illustrates the various approaches that public project owners can take to implement ECI.

In addition to a literature review, three groups of case studies were carried out. The case studies were based on 54 semi-structured in-depth interviews with key personnel from 21 Norwegian public projects and document study.

In all, 25 approaches to ECI were identified during the research. Twelve of these were used in the cases studied.

There are several approaches to ECI that are suitable for public owners. However, the contractor’s contribution depends on which approach is implemented and how it is implemented.

As original contribution, this study presents a novel framework that defines options for implementing ECI in public projects. Furthermore, this paper provides insights on how ECI can be implemented in public projects based on Norwegian experiences. Although the empirical data of the study is limited to Norwegian public projects, this study contributes to knowledge about how to implement ECI internationally.

In responding to global issues of creating sustainable development, the Indonesian government has enacted regulations (i.e. Ministry of Public Works and Housing No. 05/PRT/M/2015) on the implementation of sustainable construction in infrastructure project execution. The purpose of this paper is to evaluate the means of implementing sustainable principles in the execution of infrastructure projects in Indonesia by the main construction service providers and their partners. A lesson-learned is presented as a source of knowledge to underpin the extensive implementation of sustainable principles in the construction of infrastructure projects leading to an integrated approach in creating a sustainable infrastructure that fulfills the requirements of sustainable development.

The method used is questionnaire surveys with Indonesian construction practitioners who are working on building construction, road and bridge construction, water facilities construction and house and settlement construction.

From the results, the practices of sustainability principles by construction service providers in infrastructure project execution are imperative from the project procurement phase. The evaluation continues to the phase of construction project execution, which reveals the inconsiderable performance of sustainability indicators due to current constraints on the implementation of sustainability principles.

This research looks into the existing gaps between sustainable construction principles and their practical implementation in Indonesian infrastructure projects. This will foster a holistic approach in the practice of undertaking sustainable procurement processes, thus reinforcing project management techniques in the phase of sustainable construction project execution. This also strengthens the interrelated roles and responsibilities of project stakeholders by taking into account principles of safety, balance and the harmony of infrastructure and the environment.

A key factor adversely affecting contractor social networking performance is the improper handling and information management of contractor’s services delivery on websites. Contractor social networking is particularly problematic on industrialised building system (IBS) infrastructure maintenance projects where contractor’s certified quality product and firms are not matched with maintenance specialisation services. The paper aims to discuss this issue.

This paper reports on the early stages of research which is developing a new information and communications technology (ICT)-based approach to managing contractor social networking on IBS infrastructure maintenance schemes. As a precursor to this work, the paper reviews current contractor social networking websites practices on IBS infrastructure maintenance projects and explores the ICT tools and techniques currently being employed on such projects.

The findings reveal the need for more sophisticated contractor social networking websites solutions which accord with the needs of IBS infrastructure maintenance schemes.

The paper concludes by presenting a research framework for developing such a system in the future.

The recent promotion of prefabricated housing (PH) in China has resulted in a prosperous period for its implementation. However, transaction costs (TCs) cause low economic efficiency to stakeholders and hinder the further promotion of PH. No relevant study has yet been made to investigate the TCs and their causes in the PH field. This paper identifies critical TCs and explores the influencing factors from the developers' perspective.

Semi-structured interviews and a questionnaire survey were used to collect data about TCs and influencing factors. The most influential factors are identified with their impacts on particular TCs, yielded from correlation analysis and logistic regression.

From the developers' perspective in China's PH market, this study identified that the most concerning sources of TCs are: hidden costs arising from disputes, extra workloads from design changes, learning costs, intensive communication and coordination in assembly and unexpected information costs in decision-making. The use of an ordered logistic regression approach indicates that the four most influential factors are: qualification of the general contractor, mandatory local policies, owner type and competitiveness of the developer.

To reduce the TCs, experiencing learning and ensuring the design scheme's complicity are recommended to save information searching and exchanging costs. The implications for the PH developers are for them to: (1) professionalize their own organization and (2) procure high-qualified general contractors. For the policymakers, this means they should improve the clarity of the mandatory local policies for PH step-by-step.

By applying the TCs economic theory, this study explores factors that influence TCs in the PH industry. It sheds light on the influencing mechanism behind the TCs in the context of prefabricated housing.

Labour productivity in construction has fallen behind other industries in most of the world and has declined continuously for decades. Although several scholarly research projects have been conducted to salvage the prevalent low labour productivity in construction, contractors in the construction industry have continued to grapple with the devastating impact of low productivity. The purpose of this study is to determine key areas of focus necessary to promote productivity growth in construction.

Bibliometric and scientometric assessments were conducted to map the existing construction labour productivity (CLP) studies and establish key focus areas in the research domain. The keywords “Construction Productivity” OR “Construction Labour Productivity” OR “Construction Labor Productivity” OR “Construction Worker Productivity”.

Emerging trends in the CLP research field are reported. The study also determined the most productive authors and collaboration among authors, most productive journals, most active regions and publications with the highest impact in CLP research.

Documents published in the Scopus database were considered for analysis because of the wider coverage of the database. Journal and conference articles written in English language represent the inclusion criteria, while articles in press, review, book chapters, editorial, erratum, note, short survey and data paper were excluded from analysis. The study is also limited to documents published from 2012 to 2021.

The study brought to the awareness of the industry practitioners and other construction stakeholders, the key knowledge areas that are critical to promoting productivity growth in construction.

Except bibliometric analysis, previous research studies have used different approaches to investigate productivity in construction. The study presented future research directions through the emerging knowledge areas identified in the study.