Search results

In Bangladesh (BD), delays in infrastructure are common. Many previous studies have explored the causes of infrastructure delays. However, this study investigated the causes of delays by taking responses from the stakeholders who are responsible for planning, design, funding, approval and implementation. There are few studies that have related infrastructure project delays to heterogeneity in stakeholders’ perceptions.

A structural equation (SE) model is developed with 350 normally distributed data points to understand the heterogeneity in stakeholders’ perceptions regarding delays in infrastructure projects in BD. Additionally, the relative importance index (RII) approach is used to assess the responses, validating the SE model.

The study finds that among the three latent variables, “Project itself related delay” has more influence on delays in infrastructure projects. Among the observed variables under the “project itself related delay” latent variable, “DPP approval process” has the most significance. From the heterogeneity analysis, the study found differences in responses among the stakeholders from “the Engineering Department,” “the Planning Office” and “the Construction Firm/Industry.” An important class of stakeholders believes that their stage is not being delayed and that other stages require attention.

The data sample is 350. More data can improve the accuracy of the findings. Most of the respondents are civil engineers (74%) and represent the owner of the project. Sample data from more stakeholders’ will enhance the accuracy of the result.

This study addresses the requirements of Bangladeshi project stakeholders and how their interactions cause delays in projects. Furthermore, the opinions of other stakeholders are taken into consideration when determining the specific factors of individual stakeholders that are causing delays. Practically, the distance between stakeholders should be reduced. A project manager can play a role in this regard. Initiatives should be taken on how to complete the project quickly by eliminating the requirements discussed among the stakeholders and bureaucratic complications. Instead of placing blame on one another, stakeholders should take the initiative to figure out how to work together to finish the project on schedule. The Planning Commission’s approval of the Development Project Proposal (DPP) and Revised Development Project Proposal (RDPP) should be obtained as soon as possible by owner stakeholders. In order to avoid frequently changing the DPP, owners should also exercise greater caution when choosing contractors. Contractor stakeholders should use efficient and proper manpower and equipment so that unexpected delays are not created during the execution of work. Since the role of the contractor stakeholder is the most important among the three types of stakeholders, the contractor should raise awareness and urge the owners to get the RDPP approved quickly.

The findings from the study can help mitigate delays in infrastructure projects in BD, taking into account the perceptions of various stakeholders.

Construction project stakeholders can have a major effect on delivering projects on time. However, little attempt has been made to address the influence of internal stakeholders on delaying project delivery. This research aims to propose the internal stakeholders' influence as a solution to improving project delivery performance (PDP) in order to boost the value of investment in the construction industry's projects.

In Yemen, a structured questionnaire was distributed to owners, consultants and contractors, 283 of which were found usable after the data screening. A purposeful sampling technique was used and structural equation modelling (SEM) was adopted for analysis. The structural model was drawn up, based on seven categories of influencing factors: labour, supplier, designer, contractor, consultant, sub-contractor and owner.

The results of the structural model suggest that of these seven categories, designers, owners, suppliers and subcontractors have a significant p-value and impact on PDP, while the labour and consultant's impact was not substantiated. The findings support the proposal that internal stakeholders' influence contributes directly to construction PDP.

The influence of stakeholders on PDP is important. Nonetheless, few studies have focussed on their effectiveness, especially in developing countries. This paper's contribution is evaluating the cause–effect relationship between stakeholders' influence and construction PDP through analysis of moment structures (AMOS) analysis. The policy implications of the research are to encourage governments in general and construction companies in particular to take responsibility for improving PDP, as slow execution of construction projects leads to increased costs, failure and abandoning projects.

This study aims to investigate the role of Islamic finance in supporting sustainable economic growth, innovation and digital transformation in the Gulf Cooperation Council (GCC) region. Amid global challenges like the Russia–Ukraine conflict and COVID-19, the focus extends beyond the GCC’s oil dependency to explore how Islamic finance can enable technological advancements and foster a digitally innovative economy. The research aims to reveal the potential of Islamic finance in driving economic diversification, technological progress and sustainable development in the GCC.

Using a content analysis approach, this study critically examines the economic repercussions of recent global crises, shedding light on how Islamic finance contributes to socio-economic justice and the provision of social goods in the GCC. The research synthesises findings from various secondary sources, including academic literature, reports and industry standards, to analyse Islamic finance’s role from an ethical and strategic perspective within the GCC’s evolving economic landscape.

The findings reveal Islamic finance’s potential to significantly contribute to the GCC’s economic diversification and resilience against global economic downturns. The study highlights how Islamic finance aligns with the sustainable development goals and its effectiveness in promoting ethical financial practices and socio-economic justice.

Future research should focus on global comparative studies to understand Islamic finance’s impact on sustainable development beyond the GCC. Longitudinal studies are also essential to assess the long-term effects of Islamic financial instruments on economic stability.

The research advocates for incorporating Islamic finance principles into the GCC’s economic strategies, emphasising its role in providing resilient and ethical financial alternatives conducive to sustainable development. It underscores the need for policy initiatives integrating Islamic finance to bolster socio-economic welfare and environmental sustainability.

Offering a novel perspective, this paper enriches the discourse on the contribution of Islamic finance to sustainable economic development. It presents critical insights into how Islamic finance can underpin long-term economic resilience and growth in the GCC. It provides valuable implications for academia and policymaking, particularly in emerging economies’ science and technology policy management.

This study aims to examine how digitalization affects the work efficiency of the Shariah Supervisory Board (SSB) in Islamic banks.

This study uses panel data analysis of annual report disclosures over the past 10 years. The authors have selected 79 Islamic banks for the period ranging from 2012 to 2021. The criteria for SSB efficiency used in this research are disclosure of Zakat and disclosure in the SSB report.

The econometric results show that digitalization has a positive effect on improving the work efficiency of the SSB in Islamic banks. Accordingly, the authors provide evidence that the higher the bank's digital engagement, the higher the quality of the SSB.

The findings highlight the need to improve the current understanding of SSB structures and governance mechanisms that can better assist Islamic banks in engaging in effective compliance with recent governance and accounting reforms. Moreover, Islamic banks are the most capable and appropriate to implement and activate digitalization because they are based on a vital root calling for development if there are executives believing in it, as well as legislation supporting and serving them.